The URL can be used to link to this page

Home My WebLink About1325-R0004_PERSON_HALL_HVAC_AND_RE-ROOFING_FINAL_REPORT.pdf• • . - • • • • • • • • • • • • • • • • • • • • • • ·-• • • • • • FINAL REPORT Obj No: 1325-R0004 FI~..A~ .REf.O.RT I I Person Halll HVAC and Re-Roofing University of North Carolina at ·Chapel Hill Budget Code: 40392 Item: 307 and 321 FILE COPY , . .. ,. FEB 1 3 71V'P, CONSTRUCTION . MI.\.NAGEMENT HagerSmith Design, PA 12/31/07 I 10 · HagerSmlth oesign PA Interior Design • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • FINAL REPORT Person Hall HVAC and Re-Roofing Code #40392 Items 307 and 321 HSD Job #500-908 1. 2 . 3 . I General Description 1 I Person Hall is an 1-plan, Georgian Revival $tyle masonry building with intersecting gable roofs. The two end pavilions are high one-story, while the connecting central section has two stories. the second story being a mechanical room. The building is located in the center of the older portion of campus, ii'ITlmediately adjacent to McCorkle Place . Date of Opening Bids: 25 Mdy 2006- Award of Contract: 20 Ju1e 2006 Work Began: 7 August 2006 Final Inspection: 7 May 2007 Date of Acceptance: 7 Ma~ 2007 Expiration of Guarantee: 7 Ma~ 2008 The basement/crawlspace of the building i~ unfinished and is devoted exclusively to piping. The first floor has performance spabes at either end, connected by a central, double-loaded corridor with offices/practice rooms and toilets. An upper level over the central wing serves as a mechanical room . Exterior Design The exterior of the building is hand-molded brick masonry with sheet metal formed cornices and wood windows and doors. The windows and doors are round-arched, with double-hung wood window sash and wood doors. Along both elevations of the central wing are round-arched blind windows. Adj,cent to the west elevation is a raised terrace paved with stone. j Person Hall's roof is decked with cast gyps~m planks. The planks are waterproofed with a self-adhesive bituminous membrane, topped with red rosin paper. The exposed roof membrane consists of a standing seam copper roof with barrel-arched vent dormers . There is no insulation in the roof system. ~utters are copper, half-round, double-roll type suspended from the roof pans on adju~table brass hangers. The downspouts have conductor boxes and are round in section. They terminate into cast iron boots that are connected to the subsurface drainage syst m . Interior Construction and Finish Person Hall is classified as a Business ~ccupancy. The type of construction is Ill-B . -ihe existing interior wall finish is painted g psum wallboard. Flooring throughout the lower level is glue-down carpet, VCT, or Ia inate. The mechanical room has an exposed concrete floor. The ceilings in the Recital Hall and Choral Room are dished Person Hall HVAC and Re-Roofing Page 1 of 31 Final Report I • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • 4 . 5 . 6 . plaster with suspended gypsum wallboard/wood soffits. The baseboards, window and door trim, and windows and doors are of painted wood . Structural Person Hall is constructed with common brick load-bearing masonry on the exterior, and between the two end pavilions and the center hall. The existing 1970s interior structure of the building has reinforced concrete interior basement foundation walls and steel pipe columns on the first floor. Both levels have concrete floor slabs. The existing roof structure of the building is framed with hot-rolled steel trusses with steel channel purlins and cast gypsum planks for the roof decking . Plumbing Domestic water was provided on this project to serve stand-alone humidifiers. Drains from air handling units were routed from the units to existing floor drains located in the mezzanine mechanical room . Mechanical This project provided a transitional HVAC renovation of Person Hall until an anticipated more comprehensive renovation/restoration is performed at a future date. An existing HVAC system installed in the 1970's was found to be exceptionally noisy, and all conditioned spaces were found to have indoor air quality issues. This project included the replacement of all air handling units and related above-ceiling ductwork, the provision of sound attenuating plenums in supply and return air streams between the Choral Room and Recital Hall, and the mechanical room. The air handling units were provided with variable frequency drives to permit operation at low flows to provide reduced cooling capacity and simultaneous dehumidification. The air handling units were also provided with economizer (free cooling) sequence to permit the ability to take advantage of outdoor ambient conditions for the cooling of the building without the use of chilled water. Equipment and materials were provided for positive building pressurization, de-humidification and humidification, and precise temperature control. During design it was recognized a desire for the future elimination of the existing mezzanine mechanical room and raising of all equipment to an attic location. All equipment and ductwork was located in such a way to permit the future relocation of HVAC equipment directly upward . The chilled and heating hot water systems were replaced from the point of entry into the building to the final users. New pumps and hot/chilled water bridge controls were provided in accordance with UNC-CH Guidelines . New DDC temperature controls as provided by Johnson Controls were installed in the building. The controls were provided with an interface to the existing campus-wide system . Valuable instruments and other items were stored in the Recital Hall during construction . A temporary HVAC system was designed in conjunction with the University to provide temporary conditioning of the storage space . Person Hall HVAC and Re-Roofing Page 2 of 3 Final Report • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • 7 . 8 . 9 . Electrical The existing electrical system was modified as necessary to support the replacement of the HVAC systems. Most electrical service panels were retained . A VESDA aspirating-type fire alarm system was installed to monitor conditions in the Recital Hall. The system will provide earliest warning of smoke and/or fire in the space while minimizing the visual impact on the historical space. The existing fire alarm system was upgraded by the University's forces during the project. Elevators There are no elevators in the building . Exhibits (Attached) Exhibit A: Square Footage Figures Exhibit B: Cost Data Exhibit C: Change Orders Exhibit D: Subcontractors & Suppliers Exhibit E: Energy Criteria 10. Attached Certificates Certificate of Completion Certificate of Compliance -Architectural Certificate of Compliance -PME Person Hall HVAC and Re-Roofing Page 3 of 3 Final Report • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • "EXHIBIT A"-SQUARE FOOTAGE FIGURES Person Hall: Gross Square Footage: ............................................ 8,140 Usage Classification: ....................... Net Square Footage: Offices ........................................................................ 1 060 Classrooms ................................................................ 1794 Corridors/Lobby ........................................................... 695 Toilets .......................................................................... 185 Mechanical ................................................................ 3885 Janitorial/Storage ........................................................... 58 Total Net Square Footage: ...................................... 7,677 Gross/Net Difference: (8140 -7677) X 100/8140 = 5.69% A-1 Percent Total Net: 13.8% 23.4% 9% 2.4% 50.6% .8% 100.0% • • "EXHIBIT B"-COST DATA • Single Prime Contract: Original Contract Amount: Change Order: GC-1: GC-2: GC-3: Total Change Order Amount: • • • • • Total Single Prime Contract Amount: • Subcontractor Schedule of Values: • • • • • • • • • • • • • • • • • • • • • • • Subcontractor: Mechanical: Electrical: Fire Alarm Subsurface Drainage Roof Masonry Totals: Total Design Fee: Original Fee Amendment #1 Additional Services Other Owner Costs: TOTAL PROJECT COST: Original Subcontract: 252,535.00 19,819.00 18,750.00 18,700.00 235,150.00 12,616.00 $557,570.00 Change Orders: 47,568.75 661.00 10,750.57 0.00 0.00 4,000.00 $62,980.32 B-1 $25,849.00 $20,704.00 $24,955.00 Total Subcontract: $300,103.75 $20,480.00 $29,500.57 $18,700.00 $235,150.00 $16,616.00 $620,550.32 %Total Project Cost: 34.8% 2.4% 3.4% 2.2% 27.3% 0.02 72.0% 95,590.00 4,550.00 15,590.00 $790,059.00 $71,508.00 $861,567.00 $115,730.00 Not Provided $977,297.00 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • "EXHIBIT C" -CHANGE ORDERS General Contract: Change Order: Amount: 1 2 3 Description: Add VESDA system to project, additional cost for expediting AHU delivery, additional cost for entry return duct.. Replace hot water system controls Remove stumps at front of building, repair gypsum roof deck planks, re-route return air ductwork at Recital Hall, credit for removal of Fire Alarm System from contract, credit for repair of cornices, additional cost for relocating guy wires in attic, additional cost for cutting concrete under brick walks and removing stone under rear terrace, additional cost for adding mylar to ductwork, additional cost for re-piping hot water for convection heaters, additional cost for adding quad outlet in Janitor's Closet TOTAL CONTRACT CHANGES: C-1 $25,849.13 $20,704.00 $24,955.00 $71,508.00 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • "EXHIBIT D" -SUBCONTRACTORS AND SUPPLIERS Temporary and pennanent Seegars Fence Company fencing Site Utilities Southern Piping Company Roofing P & R Roofing Company P.O. Box 46089 Raleigh, NC 27620 P. 0. Box 90455 Raleigh, NC 27675 1212 Marstellar St Wilmington, NC 28401 D-1 919-231-5473 SUPPLIER 919-957-7228 SUBCONTRACTOR 910-343-0509 SUBCONTRACTOR • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • "EXHIBIT D" -SUBCONTRACTORS AND SUPPLIERS Mechanical Comfort Engineers, Inc. Fire Alarm American Fire Technologies Electrical Sir Walter Electric P.O. Box 2955 Durham, NC 27715-2955 818 Tyvola Road, Suite 108 Charlotte, NC 28217 463 Hein Drive Gamer, NC 27529 D-2 919-383-2502 SUBCONTRACTOR 704-679-9506 SUBCONTRACTOR SUBCONTRACTOR • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • SECTION 326 CERTIFICATE OF COMPLETION; PROJECT: Person Hall HVAC and Re-Roofing LOCATION: University of North Carolina at Chapel Hill SCO ID NUMBER: - BUDGET CODE: 40392 Item: 307 and 321 Date: 19 December 2007 OWNER: University of North Carolina at Chapel Hill DESIGNER: HagerSmith Design, PA PRIME CONTRACTOR: Fabco Construction, Inc . I certify that all work on the above referenced project has been completed according to the plans, specifications, addenda and approved change orders and that the project is ready for owner occupancy . The final inspection was made on 7 May, 2007. The guarantee period begins on 7 May 2007, and shall terminate on 7 May 2008 . The contractors report that final payments have been made to all material suppliers, employees and subcontractors, and copies of their lien waivers are attached . Builder's risk insurance was cancelled as of 7 May 2007 . The total time for completion as allowed in the contract plus granted time extensions is 159 days. The actual time required for completion was 273 days, and the contractor is liable for liquidated damages. The contractor has not been notified of any proposed assessments of liquidated damages. Copies of my letter of recommendations as to the amount of liquidated damages are attached . Copies of the following items are attached as indicated below: Written guarantees: Affidavits: Fabco Construction, Inc. P & R Roofing, Inc . Contractor's Affidavit of Payment of Debts and Claims Contractor's Affidavit of Payment and Release of Liens Contractor's Affidavit of Release of Liens Subcontractors' Affidavits of Release of Liens Consent of surety company to final payment. Manuals of Operations/Instructions: Delivered Previously Final report: To be delivered separately As-built drawings: To be delivered separately . Other required closing papers of the contractor: None • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • There are no unsettled disputes between the owner and contractor, owner and designer, or the designer and contractor at this time& Signed this / ff/1 day of ~20[2. ~~/;JJ,I/11! Designer (SEAL) Title: Project Architect/HagerSmith Design, PA • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • HagerSmilh oesign PA Architecture Landscape Architecture Planning Business Interiors Construction Management 300 South Dawson St Post Office Box 1308 Raleigh, NC 27602 919 821 5547 919 828 4050 fax www.hagersmith.com June 15, 2007 L. Craig Baker, PE Facilities Planning The University of North Carolina at Chapel Hill CB# 1090 1 03 Airport Drive Chapel Hill, NC 27599-1090 Re: Person Hall HVAC and Re-Roofing Code: 40392 Item: 307 and 321 Dear Craig: Fabco Construction Company, Incorporated, has informed me that they do not plan to ask for any additional days on their contract. Therefore, our assessment of potential liquidated damages is: Contract Completion Date: 12 January 2007 Substantial Completion Date: 7 May 2007 Days subject to liquidated damages: 114 Liquidated damages per contract: $300/day Total potential liquidated damages: $34,200.00 Sincerely, Cc: Lindsey Hopkins Jim Smith 1 • • • • • ~1~ HaoerSmllb oesign Pi-\ Architecture Landscape Architecture Planning Business Interiors Construction Management • 5 July 2007 • • • • • • • • • • • • • • • • • • • • • • • • • • MEMORANDUM To: M. Lindsey Hopkins UNC-CH Construction Management From: David R. Black, AlA Re: Fabco Construction Company, Inc., Request for Additional Contract Time Bids were opened on 25 May 2006. An award recommendation was made on 31 May 2006. The project was awarded by UNC-CH on 21 June 2006. Due to Contractor delays in getting bonds and insurance certificates required for the contract, the pre-construction conference was not held until27 July 2006, and the Notice to Proceed was given as of 7 August 2006. Roof demolition did not begin until the third week in September and in-fill framing and gypsum sheathing were not complete until the first week in December. The roofers were not able to begin drying-in until early November. Delays in General Contractor mobilization, beginning roof demolition, and completing the roof infill seriously delayed the beginning of HVAC installation and the completion of the finished roof . Although there was rain during the fall, and particularly in September, National Weather Service statistics indicate that the overall rainfall during the roof construction period was in line with the average of the previous five years, as stated in the Contract. No contractor diaries have been provided to indicate otherwise . Air handlers, piping and ductwork were complete by 9 March 2007, but the variable frequency drives were delayed and were not installed until the week of 14 March, delaying start-up for the HVAC units. The delay in getting the proper VFDs and installing them more than wiped out any delays prior to that time for mylar ductwork liners or the revised return air arrangement at the Recital Hall. In regard to the Hot Water Controls, Carter & Burgess first noticed many of the control elements laid out on the mechanical room floor on 20 September 2006. These were items installed after the design process had been completed. Carter & Burgess advised that they would provide a sketch for re-installing the items in the corrected location. Said sketch was provided to Comfort Engineers on 21 September 2006. On 29 December 2006, Carter & Burgess received an e-mail from Comfort Engineers regarding the identity of control devices. The existing devices had been disposed of. Carter & Burgess confirmed Person Hall Completion Memo Page 1 of2 300 South Dawson St, Post Office Box 1308 • Raleigh, North Carolina 27602 • Phone (191)821-5547 Fax (191)828-4050 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • on 3 January 2007 that the devices were required. A change order proposal was submitted on 1 February 2007. Due to confusion among the designers, the change order was not prepared unti126 February 2007, and was not approved by UNC-CH until28 March 2007. The hot water controls appear to have been installed by the end of April, 2007. No information has been provided by Comfort as to when the components for the hot water controls were ordered and when received. There was clearly a delay at the end of the project caused by lack of hot water controls, but there were also three months at the end of 2006 when the hot water controls issue could have, and should have, been resolved . At the pre-final inspection of 22 March there were other HVAC issues that did not allow for Owner Acceptance. These items included incomplete BAS controls, no test and balance, a supply duct connected to a fan inlet over the Recital Hall and a missing supply grille in the Choral Hall. No hot or chilled water had yet been supplied to the building by the University, nor had the fire alarm system been installed by the University. As of the 301h of April, the missing supply grille had still not been installed. Exactly how much the failure of the University to provide hot and chilled water and to complete the fire alarm system delayed DOl inspection is not clear. I recommend that the University give Fabco ten days for miscellaneous delays . It should be noted that in no case has Fabco Construction requested additional time as part of a Proposed Change Order for work on Person Hall. All requests for additional time have come at the end of the project, and have included signed and approved change orders for which Fabco requested no time when they were executed . Person Hall Completion Memo Page 2 of2 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • Date: 01/24/08 Fabco Construction, Inc . 144 N. Cherry St. Ste. 7 Kernersville, NC 27284 Phone: 336-992-1810 Fax:336-992-1814 Designer: HagerSm.ith Design P A Designer: 300 South Dawson Avenue Raleigh, NC 27602 RE: Dear Sirs: Project Name: Person Hall HV AC & Re-Roofing ID#: 40393 Item: 307 ID#: 40523 Item: 320 The above project was completed on _05/07 /07 __ , which establishes the beginning of all warranties . Sincerely, fLf~ Chris Fabrizio Fabco Construction, Inc . • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • July 12,2007 Mr. Craig Baker Fabco Construction, Inc . 144 North Cherry Street Suite 7 Kernersville, NC 27284 (336) 992-1810 Office (336) 992-1814 Fax The University ofNorth Carolina@ Chapel Hill Person Hall HV AC and Re-roofing Giles Homey Building 103 Airport Drive Chapel Hill, NC 27599 Re: Twelve-Month Guarantee-Project Person Hall HV AC and Re-Roofing UNC- CH Code# 40392 Mr. Craig Baker: This guarantee covers all materials furnished on this project above for one year from the Date of acceptance. Items having defects in materials of workmanship from manufacture will be replaced at no cost to the owner . Fabco Construction, Inc. guarantees the workmanship of its labor to be free from defects for one year. We will correct any problems resulting from poor workmanship or neglect of said employee or sub contractors at the expense of said company . Please call (336) 992 -1810, if there are any questions concerning the extent or conditions of the guarantee . Sincerely, Fabco Construction, Inc. tLr: -;;-~ Chris K. Fabrizio President • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • ~ l?&ru~oonxl,.l?"C' • "" jl) 11\1 3·131l5:1!\) P & R Roofing, Inc . Roofing Installer's Warranty A. Whereas P & R Roofing, Inc. of 4526 Fountain Dr. has performed roofing and associated work on the following: • Owner: University ofNorth Carolina at Chapel Hill • Name: Person Hall • Address: 103 Airport Drive • Building Type: Office • City, State: Chapel Hill, NC • Area of Work: Roof • Project Acceptance Date: May 7tb., 2007 • Warranty Period: 2 Years • Expiration Date: May 7tb., 2009 B. And whereas P & R Roofing, Inc. has contracted (either directly with Owner or indirectly as a subcontractor) to warrant said work against leaks and faulty or defective materials and workmanship for designated Warranty Period, C. Now therefore P & R Roofing, Inc. hereby warrants, subject to terms and conditions herein set forth, that during Warranty Period he will, at his own cost and expense, make or cause to be made such repairs to or replacements of said work as are necessary to maintain said work in a watertight condition . D. This warranty is made subject to the following terms and conditions: a Specifically excluded from this Warranty are damages to work and other parts of the building, and to building contents, caused by: 1. lightning; 2. peak gust wind speed exceeding 110 mph (m/sec ); 3. fire; 4. failure of roofing system substrate, including cracking, settlement, excessive deflection, deterioration, and decomposition; 5. faulty construction of parapet walls, copings, chlmneys, skylights, vents, equipment supports, and other edge conditions and penetrations of the work; • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • E. 6. vapor condensation on bottom of roofing; and 7. activity on roofing by others, including construction contractors, mamtenance personnel, other persons, and animals, whether authorized or unauthorized by Owner. b. When work has been damaged by any of foregoing causes, Warranty shall be null and void until such damage has been repaired by P & R Roofing, Inc. and until cost and expense thereof have been paid by Owner or by another responsible party so designated. c. P & R Roofing, Inc. is responsible to damage to work covered by this Warranty but is not liable for damages to the building or building contents resulting from leaks or faults or defects of work. d. Dming Warranty Period, if Owner allows alteration of work by anyone other than P & R Roofing, Inc., including cutting, patching, and mamtenance in connection with penetrations, attachment of other work, and positioning of anything on roof, this Warranty shall become null and void on date of said alterations, but only to the extent said alteration affect work covered by this Warranty. If Owner engages P & R Roofing, Inc. to perform said alterations, Warranty shall not become null and void unless P & R Roofing, Inc., before starting said work, shall have notified Owner in writing, showing reasonable cause for claim, that said alterations would likely damage or deteriorate work, thereby reasonably justifying a limitation or termination of this Warranty . e. During Warranty Period, if original use of roof is changed, this Warranty shall become null and void on date of said change, but only to the extent said change affects work covered by this Warranty . f. Owner shall promptly notify P & R Roofing, Inc. of observed, known, or suspected leaks, defects, or deterioration and shall afford reasonable opportunity for P & R Roofing, Inc. to inspect work and to examine evidence of such leaks, defects, or deterioration. g. This Warranty is recognized to be the only warranty ofP & R Roofing, Inc. on said work and shall not operate to restrict or cut off Owner from other remedies or resources lawfully available to Owner in cases of roofing failure. Specifically, this Warranty shall not operate to relieve P & R Roofing, Inc. of responsibility for performance of original work according to requirements of the Contract Documents, regardless of whether Contract was a contract directly with Owner or a subcontract with Owner's General Contractor. In witness thereof, this instrument as been duly executed this th day of May, 2007. ft I f'\c\ a. Authorized Signature:-j~9F""""""'ze,.,.,.~~~------- b. Name:Ad<!l.!M. :I)ofii"!...k!.AA! c. Title(i).;r~:.u:!I1W.\ Nc.n~r II Jun 29 2007 7:45 HRGERSMlTH DESIGN 828 4050 p.l --~~~--------------------- II II •• II II Owner D Designer 0 Contractor 0 ·Code Item Surety. 0 -other ·D . Qse With State of North Carolina Proj~cts · • . CONTRACT-FOR: · . CONTRACT DATE: .· undersigned, pursuant-to Articlb ·3s of the. Geoer~l Conditions of the Contract. hereby ~ has paid in full. of has otherwise satisfied all obligations for aU materials ancJ equipment nlnf!ti!:tt-u::!rt for all work. labor ana services performed. and for aU known indebtedness and. clain':ts ·contractor for damages arising in any manner in connection with the peno~ance of the db~lttract re~nced above far which the owner·or -his property might in any way·be held. responsible. . . SIUPPI:m-nNG Q9CUMENTS ATTACHED HERETO: . . (&dDlSelrtt of Surety to Anal PaymenL Whenever surety ·js· in~olved, Consent of Surety is required. UilcJtlae attaChment f19$ ) (no ). . · : -· following supporting documents-should be attached h~o if required by·the · nm~M~r--. Contractors ·Release or Waiver of Liens., conditional upon receipt of final payment· · Separate Releases .or Waivers of Uens from subcontractors and material and equipment. suppliers to tbe extentjequired by the owner. accompanied by a list thereof. Contractor's Affimmt of Release of Uens. · . · . . ;L() ·day of .;,:~:.,~:f;i:~\ -~=~~G2L~-CROf!M~~ . !~1 NOTARY PUBLIC= . ! ~--~s .. 2CX:f]. \~2· ,., FORY~"f!i~UNTY,N.C.: I+; Comrni;;:jon Exprres 08-25-201!? j ·- ._-=_.~~ ·- • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • CONSENT OF SURETY COMPANY TO FINAL PAYMENT Owner Designer Contractor Code Item -------------Surety Other For use with State of North Carolina Projects PROJECT: UNC-Chapel Hill, Person Hall HVAC & Re-Roofing (name, address) Chapel Hill, NC TO: (Owner) University of North Carolina at Chapel Hill 1 03 Airport Drive CONTRACT FOR: HVAC & Roof Chapel Hill, NC 27599 CONTRACT DATE: CONTRACTOR: Fabco Construction In accordance with the provisions of the Contract between the Owner and the Contractor as indicated above, the (here insert name and address of Surety Company) Western Surety Company PO Box 5077 Sioux Falls, SD 57117 , SURETY COMPANY on bond of (here insert name and address of Contractor) Fabco Construction 144 N. Cherry St., Ste. 7 Kernersville, NC 27284 ,CONTRACTOR hereby approves of the final payment to the Contractor, and agrees that final payment to the Contractor shall not relieve the Surety Company of any of its obligations to (here insert name and address of Owner) University of North Carolina at Chapel Hill 1 03 Airport Drive Chapel Hill, NC 27599 AS SET FORTH IN SAID Surety Company's bond . IN WITNESS WHEREOF, the Surety Company has hereunto set its hand this 18 day of April --------------~------------- ~ (Seal} S-3981/G'CEF 11197 Western Surety Company Kitara A. Smith, Attorney-in-Fact Title ,OWNER 2007 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • Western Surety Company POWER OF ATTORNEY APPOINTING INDIVIDUAL ATTORNEY-IN-FACT Know All Men By These Presents, That WESTERN SURETY COMPANY, a South Dakota corporation, is a duly organized and existing corporation having its principal office in the City of Sioux Falls, and State of South Dakota, and that it does by virtue of the signature and seal herein affixed hereby make, constitute and appoint Sandra Booker Byrum, Phoebe C Honeycutt, Harold G Ramsey, Cynthia Green, Theresa T Siragusa, Robert G Salmon Jr, Angela Mull Britt, James P Carter, Kenneth J Peeples, Kitara A Smith, Individually of Durham, NC. its true and lawful Attomey(s)-in-Fact with full power and authority hereby conferred to sign, seal and eltecute for and on its behalf bonds, undertakings and other obligatory instruments of similar nature -In Unlimited Amounts - and to bind il thereby as fully and to the same extent as if such instruments were signed by a duly authorized officer of the corporation and all the acts of said Attorney, pursuant to the authority hereby given, are hereby ratified and confirmed . This Power of Attorney is made and executed pursuant to and by authority of the By-Law printed on the reverse hereof, duly adopted, as indicated, by the shareholders of the corporation . In Witness Whereof, WESTERN SURETY COMPANY has caused these presents to be signed by its Senior Vice President and its corpomte seal to be hereto affixed on this 17th day of October, 2006 . State of South Dakota County of Minnehaha WESTERN SURETY COMPANY On this 17th day of October. 2006, before me personally came Paul T. Bruflat, to me known, who, being by me duly sworn, did depose and say: that he resides in the City of Sioux Falls, State of South Dakota; that he is the Senior Vice President of WESTERN SURETY COMPANY described in and which executed the above instrument; that he knows the seal of said corporation; that the seal affixed to the said instrument is such corporate seal; that it was so affixed pursuant to authority given by the Board of Directors of said corporation and that he signed his name thereto pursuant to like authority, and acknowledges same to be the act and deed of said corporation . My commission expires November30, 2012 CERTIFICATE I, L. Nelson, Assistant Secretary of WESTERN SURETY COMPANY do hereby certify that the Power of Attorney hereinabove set forth is still in force, and further certify that the By-Law of the corporation printed on the reverse her my name and affixed the seal of the said corporation this l8 day of _ __j~'-4!!Z...-~.o:=. ____ , -"'"""-""--"- WESTERN SURETY COMPANY Form F4280-09-06 • Jun 25 2007 7: 45 HAGERSMITH DESIGN 828 4050 • • • • •• • • • • ' ! . : l ' i · . . .AlHZJAJllT OF CONT.Jl4CTOR (Release) .· i Stu.te of 1/41.?:rnt (A.~~ A/A n r!oan~ of r.-r .,.~ It C~!: @d~c : . _ ; (t:ffie) /i.sl.IJ_eN-r ! of(compani_rurme) &dee> ~crB?Ai;--;zzJe--~ beingfustdulyswm:n i . . . • : _ . i certify· ~t (company name) -..L.ffl.:....://:.=:~=~::-_sCc.......c~i:E~eS'T1o..::.'"""~t.,;;;=· =n'-"'-"&.~~=--,....,Ztt~uc-------- . !~asthe ~~~ •• • •• • • • • • •• • • .... • • • • • • • • • Contractor in connection \Iilith the . . i . . i constrUction. of (project name) · _?e"i!!!J?J1f? /fol-''-. #",......o. c. ( ,.,a.~~.:a e41&j-·. I ·----------~----------~----~---------------------------------~ . ~ . · J~d improvements }).a-ve beerifully-con1.~leted; to the bestof-tn.y·imowledge all j • ... - -~pa;~ents for materials, services, Or sub contra~d v.rork in connection ·with tfris i -. -.. .. . .. ~contr,act_ fuwe been satisfi~,.~ no "claims or liens exist against the Contractor in . . ironnecti9ri' with this contract; -~ .. l . i . . . !To the. best of my know1ed.ge1 no cia:ims or liens ~t against any sub contractor or jsappiier, ar:.d if any· appear afterwa+ds {CoJ:!'lpany: nani,e) __,If!~· =tz'-c.o~------'---r . ·-. . . · i (,"A/~"'r/~#. :Z:A/~ . · · hereby agrees to save I , • ~ess The State of North Ca:rolina thr?;gh the U:rl.versity of North Carolii-\a at . i ptapel" Hill. I .! 1 ! - i .l .· I· ~ubscn"bed a:.-:.rl 5wom to before: the ~"mgne.dr a Notary ~..blic: in ~d for the County and ' . . -Jr\ .t::?LA\J-..1 ~ 7-f>fateafo,~~~ _,__.:_. dtnJof ·o~~ · .,2oL_. l ' . ANGE.LACROSS .. 1 . ; ~ f. ~ -Notarif Public L-~ NOTARY PUBUC i • .• --+-~---"..~~ty¥1"""::;"'.,.........:-=~::;,::......__ tsenJ.; , FORY~l!i C~UNTY,"N~C: : . -· . /) . · . l' I My ComllllSSIOn E.--p= OS"-:::..!: -. My CommiS..c:'..OTL l:.rp1_res; :'?)" '""2=~~2.CJU! 1 --. J \adminshare\Ciose ol.!~VCON.BOC • Z::ssos . · . · .I - l p.3 • • • • • • • • • • • • • •• : • • .lun 29 2007 7:45 -1 _ RACTOR'S f I'DAVIT OF ·; . :$SB OF "LIENS HAGERSMITH DESIGN SECTiON316 owner ·o Design~r · 0 828 4050 Contractor 0 _ Code ___ Item...._ __ . surety ·o. : Other 0 . ' . Sta~e of North ·Carolina P~ojects CONTRACT FOR: p.2 ~ · un~ersigned, ·pursuant t:o Article 3~ of the. General Conditions of t:4e t~a~c, hereby certifies that to ~he best· of his knowledge, in£ormation !belief, the Releases or Waivers ·of Lien attached hereto· i"ncluQ.e. the . tira..etor, all subcontractors g al:l SUppliers Of materials and .equipntent I !all performers of work, labor 0r se~ices:who have or may have ~~ens ijnst any property Qf · the . owner ar:i:sifig in any mariner out of the t'rmance of t:J:l.e contraqt referenced above. . . ~~:[NG DOCIIMEN';rS CONTI<AC"roR' ·a.; l-1-zr~ ~.<..-~ I //"' . I" ~D HERETO: ._ Address: . · . · · · . · I By-~_}. __ ~ i i ;. l ! i 1 l i -! ' I .j I Subscribe~ arid sworn to~efore me thl:: "'J-0 day of 9q~2q ?J7 -~ctiuy Public~ My Comm~ssion Expires:~.~~~(11 ANGELA CROSS NOTARY PUBUC · FORYSTH COUNTY, N.C. My Commission Expires 08-25-2009 •• • •• • Jun 2S 2007 7:45 i f i : i - ; . i HAGERSM!TH Ut~I~N ,.. ..... ·, SEcTION316 .· · own.e:r: ·o Designer · 0 ./ · ~irnlrn:iAcTOR r s Contractor ~ Code ____ Item~---- 4 1D~VIT OF .. . Surety "0. ~·!!!=·ln-Q.E OF l.IENS Otlier {] . .. . . . ~se w~th Sta~e o£ No~h~arolina P~ojects ·~-~·~==~--------~------------------~---------0 !{OWNER. • • • • • • • : • • CONTRACT POR: f~-~ ·. 'e.· unP,ersigned, ·pursuant to Article 3~ of the. General COnditions of t}?.e t!ra~t, hereby certifies that to .the best· of his knowledge, information · !belief, the Releases or Waivers of Lien attached hereto· i"ncluQ.e. the tira.etor, all subcontractors, aJ.:l su:ppl.iers of inateria~s and .equipment, :all performers o£ work1 labor or serv-ices:who have or may have ~iens ijnst any property o.f · the . owner ar:i:s~g in any mariner out of the tprmance of ~e cont:rac;t refe:t'~ced above. i ... ! . PbRT"ING DOCUMENTS I . .i-Njr'~::BED • i • . I .: i i l .. ~ l . i 1 I· ~ . I I ~ . -i .. .. . TI~A.E MANTOOi!=l .. NOTARY PUBUC WAKE COUNTY. NC MY. COmmission Expires 10-22-2011 • • 828 ... 050 . ·.·,·. ·: .. ~ : -_: 1 .- . . :. .: '., ·. ~ .Owner ·•·• ·o . . . .· ; . . ~--. .: .;._ .{~; _;; ·'",'>; <;:·>·· oestgner-· _. o .,-:·.,--. '!'·;: .-. -. •···-.· ... . ContraCt~r ~Ode ___ Item __ _ . ·····.··,_~ sui~-· .. ·o .-.-~. · ... -... ·· .. ., .. _ ·· Other ·D .·. : .. ··_ .. _ . -.. -. . -. ·coNTRACT--FOR:.~\~ CONTRACT DATE: ~--:\ ~-:-·Dlo p • .&. . undersignecC:Pl1tstiant-tc;.Artrcre-a6.ofthe.~~l Conditions ofthe Contract, hereby certift6s . has paid m .full :.of has:.otherwise ·satisfied aU obligations for aU materials· anQ equipment ftDn:tiSt1ed. for all WOrk. ·labor ana services performed, and for all known indebtedness and. claims ·contractorfordamages arising in any manner in connection with the perfonnance of the ._ ........... -re~renced above far which the owner·or -his property might in any way be l:leld-responsible. D9ChMENTS ATIACHED HERETO: . . . g;QJilSeJrtt of S~;Jrety_to Fmal Payment Whenever surety·is·i~olved, Consent of Surety is required. triKI11:::ate attachment f{ye$ ) (no ). , . · . · -· -~~::l!lfll~ supporting documem'ts-should be >attached h~eto if required by· the · . --: .-· •. . . . . !tlonmacu:lrs·Release or Waiver of llens, conditional upon receipt of final payment· - .· ::),ElPC:U-LJ:~Ia. ·1 ~.ase.~ .. ~ \'Vaivers · of Uens from subcontrac1ors and material and ·equipment . ext:ernt:t.eouired by 1h~ · OVJrier, accompanied by a ·list 1hereof .. ~onDraaors Affil:ia9litof:Reiease of Uens. · . · _ ·. • .lu~ I 29 2007 7:45 ........... • • ·- • • • • • • • • • • • • • • •• • • • • • ·-• • • I , ! 1 ~ . i -- -- jSaid improvements !_:ta:ve been" fully-coinPleted; to tl1.e best of-my-knowledge all _ ~ {pa}'J;,n~ts for ~teriaJs, S~C~r Or sub contra¢ed work in COnn~on with this )contract_ have been satisfie~;~d no "claims or liens exist-against the Cozrtractor in_ -- . ~nnecti9ri with. this contrach .... .. . .. .. -! I -i --- : ~0 the-best of my knowl:edge, no cla±m.s or liens ~t against: any sub contractor or l~plier, ar..d if any-~pp~_afterwards ~Co~pan:1 :miDe) S~ ~QJ,~ ( 0 ! hereby agrees to save ~ess The State of North Carolina thr~gh the U=:rlversity of North Carolifia at ~p~~-~-~ l ~· ~£ • I -_, Title -\l,~=-~~ ..l_ .. • ~ed a-.~d ~ to befo7e the 7fllder~gned, a Notmv P¢,Zic in and for the County and f~ aforestd~ ~ . \ 0 --_ dn:y of T \.)._\~ · _ ---.. 20 O:J . ~A·E MANT{)OTH _·· . • _ Nofarjj Pub~ ~ -~ i:~RYPUBUC ~ME~~ ~ ~~~c~u~~~~ :\.0--2~ 2f2/l- :~~- · .. ·:·· • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • !II II ~ ATTACHMENTF CONDITIONAL FINAL WAIVER AND RELEASE OF LIENS AND CLAIMS BY SUBCONTRACTOR OR MARERIALMAN TO GENERAL CONTRACTOR STATE OF NORTH CAROLINA COUNTYOF Wake ------------------ WHEREAS, Seegars Fence Co Inc ofRaleigh Commercial (hereinafter "Undersigned") has been employed by D: W. Ward (hereinafter "Contractor'') to furnish _..;;._Fen=c;.::;in;:.sg,__ _________________ _ under a contract, subcontract, or purchase order dated July27, 2006 and numbered BF13520 for or in connection with the construction of improvements knows PemonHsllUNCCbapeiHiUHVAC&Re-rooling (hereinafter "Projecf'), which is located in the City of Chapel Hill County of Orange State ofNorth Carolina (hereinafter ''Property'') and is owned by UNC Chapel Hill (hereinafter "Owner'') and more particularly described as follows: Chapel Hill, NC (DESCRIBE THE PROPERTY UPON WHICH THE IMPROVEMENTS WERE MADE BY USING EITHER A METES AND. BOUNDS DESCRIPTION, THE LAND LOT DISTRICT, BLOCK AND LOT NUMBER, OR STREET ADDRESS OF THE PROJECT) . NOW, THEREFORE, conditioned only upon the receipt of 1,609.40 (amount of final payment), the Undersigned for itse~ its employees, its subcontractors, sub-subcontractors, mechanics, materialmen, and laborers, does hereby: (a) (b) (c) (d) (e) (f) Waiver of Lien Rights. Waive, relinquish, and release any and all liens, rights to file liens, claims oflien or preliminary notices of right to file lien on or against the foregoing descnoed Property, and the improvements thereon. Waiver of Bond Rights. Waive, relinquish. and release any rights it has against any labor, material, payment, performance, or lien discharge bond pertaining to the foregoing descn"bed Property and the improvements thereon. Waiver of Claims. Waive, relinquish, and release any and all claims, causes of action, suits, damages, judgments, claims and demands of any kind, character, and description, whether known or unknown, against the Contractor, the Contractor's bonding company, and the Owner, their directors, officers, principals, general and limited partners, employees, agents, subsidiaries, parent, and related corporations, successors, and assigns, arising from, pertaining to, or arising out of the :furnishing of the foregoing descn"bed materials and/or labor, the Project or the Property . All Parties Paid. Warrant and represent that it has been paid in full all amounts owed for all materials or labor furnished pursuant to the above-referenced contract and that any and all parties who have supplied labor or materials to the Undersigned for or in connection with the making of the improvement to the Property have been paid in full all amounts owed to them as a result of the performance of such labor or the furnishing of such materials . Authorization. Warrant and represent that it is the sole owner' of the claims released herein, that it has not sold, assigned, or conveyed such claims to any other party, that the individual executing this instnnnent on its behalf has personal knowledge of the matters herein stated, and is authorized and fully qualified to execute this instrument as or on behalf of the Undersigned. Initial Here: Scope ofRelease. Aclmowledge and agree that this Final Waiver and Release of Liens and Claims is a-----. independent covenant and shall operate and be effective with respect to all labor or services provided Standard Subcontract Agreement-North Carolina (4/2/02) ATL01/1060442lvl Page 8of9 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • ATTACHMENT F CONDITIONAL FINAL WANER AND RELEASE OF LIENS AND CLAIMS BY SUBCONTRACTOR OR MARERIALMAN TO GENERAL CONTRACTOR and materials furnished by, through, or on behalf of the Undersigned under any supplemental contract or contracts, whether oral or written, for extra or additionill work, and for any further labor or services provided or materials furnished at any time with respect to the Project or the Property . Given under hand and seal 02nd dayof May 2007 this Subcontractor Company Name: Signature: Seegars Fence Company of Raleigh Commercial Division _ .. __ Printed Name:. _____ ...Rick.Al:furd ---·· .--__ Title: Vice President ~~~~~----------- STATE OF North Carolina COUNTY OF Wake I, Tina E Mantooth, a Notary Public for said County and State, do hereby certify that Rick Alford personally appeared before me this day and acknowledged the due execution of the foregoing instrument. Witness my hand and official seal, this the 2nd day ofMay, 2007. -,.... (\_ SEAL ~ -zz_ ~~ TINA E MANTOOTH NOTARY PUBUC WAKE COUNTY NC My Cdifllnission Expires 10-22-2011 My commission expires: October 22, 2011 Standard Subcontract Agreement-North Carolina (412/02) A~Ol/1060442lvl (Signature). Tina E Mantooth (Printed Name) Page 9 of9 Initial Here: • •• • Jun 2S 2007 7:45 )'iACTOR 1 S f ]DAVIT OF .• . . HAGERSMITH DESIGN 828 4050 SECTION316 .. bWI'ler ·o Designer · 0 Contractor ~-Code _____ Item~--~ . surety ·o. '· Otb:er 0 Sta~e of North·Carol{na P~ojects i(OWNER}. p.2 V.,t-.l\'IJt.,~S ~ Or l'JoftTt--\ . . CONTRACT FOR: Coi'PZ.Je 5rA ~DtiJ<:r-"'5t..A.u .. : . ~or A.~t> Gt.A.~~ ~~fwt!VA: ·p.,,-Ct-tA~Z.I.. }-\ J(..l.. ! .. -L---r~·:---------~---=----' __ <==O~~T DATE: . -~ /2./ 2,t>(J} ~ qeCT.: 11:~~0~ HA\..~ • • • • • • • • • • • • • • • • • . : • u.).;) \~'-\<..~ ,.,..q ~ of: ~~ eAt:.o\...l ~A. . 1 . Ob1u.Jit:· y of = · iJ() A.\<. t_ ':. . . hie·U,D.fiersigned, ·pursuant to Article 3~ of the.General COnditions of t~e · ~~apt, hereby certifies that to ~he best· of his knowledge, information ihelief, the Releases or Waivers ·of Lien attached hereto· incluc;ie. the t~aetor, all subcontractors, arl suppliers of materials and-equipment, tall performers of works _labor E:lr serv-ices: who have or may have :liens ifnst any property o.f -the . ownel!:' arisi,ttg in any mariner out of the ~rmance of tJ:le contrac;:t referenced above . Jun 29 200? 7:45 HAGERSMITH DESIGN .. ~~.~------------------~~ 828 4050 p. 1 • • • ! -L i . . ' I j ! . ; . i •! . I ' . r . DEBTS AND CLAIMS Owner D Designer-0 Contractor ~-Code Item SuretY 0 Other -0 tise ~ State of North Carolina Proj~cts · . . --~~~!~~,.:.::.J:;,;:'E._;;j~~,~__._-__ 0 ,......,;......_,~,_._· _t=:::_:T\-\ ______ ___, CONTRACT-.FOR:_~-R. ~J~.,:)~~~~\V\ • • •• • • • • ·-• • • • • • • • • · !~~ot..\.,:)"'-A-r C:.loof~f>Z.\... ~~-CONTRAC~DATE: <l!'Z-/"Z.tJOC,. · . ie undersigned. pursuant-to Artfc~ ·35 of fhe. Gener~l Conditions of the Contract, hereby certiftSs , ihe·has paid in fuli ·or· has otherwise satisfied all obligations for aU materials anQ equipment i~hed, for all work, labor ana seiVices performed, and for all known indebtedness and. claims irist the· contractor for damages arising in any manner in conrtection with the performance of the "f:ict re~renced above for which the owner·or .flis property might in any way be beld-responsible. ,.. . . POR~G DOCUMENTS ATTACHED HERETO: . . nsent of ~tetY.to Final Pa~ Whenever surety·is·in~olved, Consent of Surety is required . hi\cficate attaChment {yS$ )~ . · . • · 1ihe following $Upporting documents-should be attached hereto if required by-the · · owner: · -.· ~-· Contractor's ·Release or Waiver of l..Jens, conditional upon receipt of final payment: · bt' ·Separate Releases -;01" -Waivers Df. Uens. fr.om_ subt;Ootractors and material and equipment . 1 suppliers to the extent:tequired by the owner, accompanied by alistlttereof. ---· · · et-Contractor's Affida'lit of Release of Liens. · · 1 IJTH dayof .··. ·····-. · . II Jun 2S 2007 7:45 HAGERSMITH DESIGN 828 4050 l • ! 1 ; • •• • t .; l i I AFI-1DA VlT OF CO.N1'fl4-CTOR (Release) . -~ • l State ol ~o.t=::tr\ ~~O\...\-~ ~ • ·. · ·1 eo!II1tyof ~A.~ 't. J! _ • . jr,~tt;~ Ekr.-s ~c~· :(title) :t=e:t.~~z:.~T • •• • • • • • • • • •• • ••••• .... • • • • • • • • • l of {compani_name) ·? & ·'R l<ooF•~&, ~C..-·:being first duly swam .! certify. ~t (company ~e) ~&; "R. . 'Ko.or=nO Er, Tee.. ! ~a9 th.e f<.o'o r \ ~c;;... . .. Conttactor in connection with the··- !const:rtlctio~ o~ (projectname) tl,s~ K>. \.J~L..L AcT lJ.~n/Z.£."§>\T'{ i ~'F ~a~~H LAR.;LUJA AX CHA~f.L HtLL J • ' I r . . .JSaid impri:nrements ~ve been· fully -con1.pleted; to the best of .m.y: knowledge all i . . ~ jpayi:n~ts for materials, sa-vices, Or sub contra~d work in connection. ·with tJris i ... . .. w • iconb".act_ have been satisfie~,-~d no "claims or liens exist against the Contractor in . . -~nnecti9ri with this contract; . ~ I . i . !To the. best of my knowledge, no cia:tms or liens ~t against: any sub contractor or /supplier, and if any· appear a£terw24ds (CoJ::!l.pany-~) ?& Y<. ·:;;:;ooE t~(T, r . .. . . . i "l?l:!>C • · . · · hereby agrees to save . ihar.n.Iess The State of North Carolina thr0U:gh the U:rlvexsity of North Carolifia at I . i . . . ~hape1:Hill. --... . .. . , .. (\ l . Signa?rre,/?a£P~F'w~.-/~ .r l . Title ~ '1. ~ '.5::> ~ \.:fT · . I . : .· .. l· . ~u.bscribed a;*!d 5-coom to befo.Tf: the r_.mde:r~igned, a Noilmj P¥blic in ~d for the County and , & • • • ~tate aforesu;id, thiS ll n\ · day of · ~ M.Bea--· .• 20 o1-: I · · ,.:·:-Nota,.YPub~" (se~!~~~;.,.:.::,::> ':·.-~---. . ·· · · 1?~ ,--v·J~)~ . Aiy-~~i~stdn £~iies: : (;;B t l9 ( a-co9 lt·~ ~--~~ 1 ~· .: ·: \ ~:.,:;. ~: --• .\r . ~~dmfi'IS!i2~ct.-jsinJ':l\AFJ)VCON..60C "i 51~--... '~t~':_::~:~~._~}:·_ .· ':·······; p.3 • • 1":54Arei •. 09/10/07 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • P & R Roofing,lnc. Customer Balance Summary All Transactions FABCO CONSTRUCTION INC • PERSON HALL Total FABCO CONSTRUCTION INC • TOTAL Sep 30,07 23,515.00 23,515.00 23,515.00 .....--l'l-\1~ "-M.O~ ~Lf"'~t...~'i.t•.YT'"e:. OV-~ lO~ ~\\o\o.!) -n-I~T '~ ~ 1-L ~t.UuE:r-f-lt'£Lb • A'-L CJ'rl-\"i.lt 'PA"«~'t.lo!l-rS t--l-h\J~ :SL'£.~ f-.l.Al\~ . AcAu.. Vc~o~~'L ~IVt'S\c.JAL. ~AG-2...~ ?.& R 'Roo.Ct ....... ~I r ~ . Page 1 l,g 17 07 11:46a • • • • • • COJ.\"TRA.CTOR ' S • AFFIDAVIT OF RELEASE OF LIENS • p.1 SECTION316 Owner 0 Designer 0 Contractor 0 Code Item surety 0 Other 0 • For Use with State of North Carolina Projects • TO {OWNERl UNC. (!:~ (!/IA·P£l.. LL CONTRACT FOR: • B~ G~ L. ~4~ . • - AS;lPC: • t/i~ -C#Jtf...vc~~ :fi... ~~ • r &w.rfr..e,f;,_ . CONTRACT DATE: • PRO.:rBCT: fbts~A.I /119-tl.. ;/ V/1<:.. I zc:e~o.,.C,....V~ ~JcG( • (name, address) ?tA(c... -eHAP€? #I t.L . County of: The undersign~d, pursuant to Article 36 of the General Conditions of the • Contract, hereby certifies that to t.he best of his knowledge, in£ormation and beJ.ief, the Releases or Waivers of Lien attached hereto· include the • contractor, all subcontractors, all suppliers of materials and .equipment, and all performers of work, labor or services who have or may .have liens • against .any property of. the . owner arising in any· mariner out of the performance of the contract referenced ab~~------------------------------------ • • • • • • • • • • • • SUPPORTING DOCUMENTS AT-TACHED HERETO: CONTRACTOR: Sir Raleigh Electric, Inc. Address: 463·H~in···n~ Garner, NC 27529 By~~ Subscribed and s·worn to before me this 18th day o~ust 20 07 .. · _ Notary ~ublico ./ij'J'I.V ~-_ My Cotmm.ssJ.on ExPl.res:·-3/9/20(j.'Q. ~ · .._ .. g 17 07 11:46a p.2 • • Jun 29 2007 7:45 HAGERSMITH DESIGN -¥~~~--------------~~--- r I llEBTS AND CLAIMS ~ I . . i .. I Owner Designer Contractor Surety- ·Other BZB 4050 p. 1 0 0 0 ·cOcle Item 0 ·0 • Use ~th State of Ndrth Carolina Proj~ · •. J_, . • ~~,;:;.;.::.:=.:.t.-__,___:_ __ .....,._,_ ____ _, CONTRACT-FOR: · • . . CONTRACT DATE: • • ~~~~~~~~~~~~~~_.~~acilities 0 • Hall HVAC & Reroofin~ Project ~~~----~~~~~~~~~~el Hill, North Carolina . _:_ North Carol in:~ • • • •• • • • • • • • • • • • • • . ·.:tohnstop He undersigned, pursuant-to ArticJ~ ·35 of fhe. Geoe~1 Conditions of the Contract. hereby certifres , jtte ·has paid in fulf ·or" has otherwise satisfied all obCigations for all materials anc;l equipment ished, for all work, labor ana services performed. and for aU known indebtedness and. claims irist the· contractor for damages arising in any manner in connection with the perfonnance of the ~.l!'ti·~ re{erenced above for which the owner·or -his property might in any way be l:leld responsible . , .. -. . .. . . FblmNGOOCUMENTSATTACHED HERETO: . · . . nsent of SUrety 1D Final Payment Whenever surety ·is· inv.oJved, Consent of Surety is required. tmdicate attaChment (YS$ ) (no ). . · .· · l'jhe foUowing supporting documents-should be attached hereto if required by· the awner: · . : a!. · Contractors ·Release or Waiver of l,iens. condmonal upon receipt of fmal payment" j ~ Separate Releases .or Y.Iaivers of Uens from subcontractors and ma'teriar and equipment" ! suppliers to tOe extentjequired by the c~er, accompanied by a list thereof . 1· Confracmr's ~ffid~~~as~ of~ . . . . · · 1 ~?~ rnACTOR:" . • · · · · . · r~s~· . S~r Rale~gh Electr~c, ~nc . -: 1 --. 11 46~ Rein ])rive, Garner, NC. 27529 . I /") p, 0·~--cJ_~ • · bri~~orn &~ .18th da~ of -• : Au st : · 2.0 0.7 . · liY ubllc: - . pmmission Expires: 3 i 9/ 2· o o a ~ . . i 0 -l·: ,_ . l .· • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • Aug 21 2007 2:10PM Aug 17 07 1 1:46a Sir Raleigh Electric 9196616554 p.4 CONTRACTOR • S AFFIDAVIT OF RELEASB OF LIENS p.1 SECTION316 Owner 0 Designer D contractor [] Code ____ ~Item~---- SUrety 0 Other 0 For Use with State of North Carolina Projects TO {OWNfiid CONTRACT FOR: (name,. address) /.L'ACt!. -CHAI'E? ri/~L ~ state of: ,!Vi,;ILrR-CA~....v'• County of: 'Xhe unders~d, pursuant to Art.i.c~e .36 of the General Conditions of the Contract, hereby certi£i.es that to the best of hi.s know~edge, information and bel.i.ef. the Rel.eases or Waivex-s of Lien attached hereto include the contractor, .a~l. sul::>contractors, al.l. suppl.iers oE materials and .equipment, and al.l. perfOl:TGers of work, 1abor or sexvi.ces wl't..o have or nia.y .have ~iens a.gainst _any property of t.he . owner arisU1g i.n any· mariner out of the performance of the contract referenced ab~~------------------------------------- SUl?l?ORTING DOCOMENTS . . CONTRACTOR: Sir Raleigh Electric, rnc. Address: ~63.iiei:n:-·n~ Garner, NC 27529 By~~ Subscr:ibed and swoJ:n to before me thls 18th daykf st 2~ 07 · .. Notary Public~ . · -=-1 / (1--:--'-~~ ~ . My commission 1res :· · 3/9/20~· .: ~~ . .. • Aug 21 2007 2: lOPM Aug 17 07 11:46a Sir Raleigh Electric .a--~~~u~n~2~S~~~C~07~~7~:~4~5~--~H~A~G~E~R~SKITH DESIGN • • • •• • • II l 1 ;· l ! • ; ! ; . l . ·! i ~ii=lk. t&Nrrf OF PAYMENT dEBTS .Awo CLAIMS I . i .. I • OWner Designer Contractor Surety Other tise Wlth State of North Carolina Proj~cts · ~ . 0 0 0 cOde 0 -0 CONTRACT-FOR: · . . CONTRACT .DATE: ~~~~~~~~~~~~~~~~~aci1ities 9196616554 828 1-050 item :· . •-· • • • •• Hall HVAC & Reroofin~ Project • II II •· • • • • • • • • • • II • • • ~~~----~~~~~~~~-w~el Hi11, North carolina North Carolin:a .· p.3 p2 p • .l IILs/Ol/2~07 os:35 FAX 919957&7&& SOU'I'HERN PIPING RALEIGH l(i003/004 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • AFFIDAVIT OF CONTRACTOR (Release) State ofNortb Carolioa Co~ of.Jobnston I, George R. PaiL (title) Executive Vice-President of (company name) Southern Piping Company. being first duly sworn certify the (company name) Soutbcm Piping Co.mpanv was tbe Plumbing Con1ractor in connection with the construction of (project name) UNC Person Halt Building. Said improvements have been mlly completed; to the best of my knowledge all payment for materials, serviceS, 01' sub contracted work in connection wi1h the contract have been satisf'led, and no claims or liens exist against the Contractor in connection with this projec:t. My To tbe best of my knowledge, no claims or liens exist against any sub contractor or supplier, and if any appear afterwaRfs (company name) Southern Piping Company hereby agrees to save harmless The State of North Carolina through the University ofNortb Carolina at Chapel HilL Subscribed Ol1d swam to lxifore the tmtlersigned. a Notary Public in and for the Cor.tmy and State qforesaid, this 161 day of Aygust. 2007 • KIMBERLY P. HOLDER NOTARY PUBLIC Johnston County North Carolina lsslon Expires MY Commission Expires: 0613012008 lls/Ol/2007 08:35 FAX 9199578768 S01JTBBRN PIPING RALEIGH lgj0011004 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • FAX MESSAGE SOUTHERN PIPING COMPANY FAXNUMBE~·-------------DATE: r/fo, RE: U d C flrse::s,-. +J.e-1 I NUMBER OF PAGES .;If INCLUDING THIS ONE. (IF YOU DO NOT RECEIVE ALL PAGES, PLEASE CALL ASAPU1) r ~-, MECHANICAL CONTRACTORS P.O. BOX 904551RALSGH. N.C. 27615IPHONE (919) 957-72281FAX {919) 957-8768 1108/01/2007 08:35 FAX 9199578768 SOUTHERN PIPING RALEIGH la!004/004 II II II • II II II • II • II • • II • • II II • II II • • II • • • • • II II CONTRACTOR'S AFFIDAVIT OF RELEASE OF LIENS CONTRACTOR'S SECTION316 AFFIDAVIT OF RELEASE OWner 0 Designer 0 Contractor • Code Surety 0 Other 0 OF LIENS; ,Item. For Use with State of North CaroLina Projects TO (OWNER) State of North carolina through University of North Carolina Chapel Hill Chapel Hill, NC CONTRACT FOR: Plumbing ~------------------------------~CONTRACT.DATE: PROJECT: UNC Person Hall Building S. Cameron Road Chapel Hill, NC State of: North CaroLina County of: Johnston The undersigned, pursuant to Article 36 of the General COnditions of the Contract, hereby certifies that to the best of his knowledge, information and belief, the Releases or Waivers of Lien attached hereto include the contractor, all subcontractors, all suppliers of materials and equipment, and all perfor.mers of work, labor or services who have or may have liens aga:Ln.st any property of the owner arising in any manner out of the performance of the contract referenced above • SUPPORTING DOCOMENTS ATTACHED R.ERETO: KIMBERLY P. HOLDER NOTARY PUBUC Johnston County North Carolina MY Commission Expires CONTRACTOR: Southern Piping Company Address: By Subscribed and sworn to before me this 1st day of August, 2007 Notary Public~~~ My Commission Expi~:' 06/30/2008 • • • • • • • • II II • • • • a II • • • • • • • • • • • a • • • • SECTION316 CONTRACTOR'S AFFIDAVIT OF RELEASE OF LIENS; Owner D Designer D CONTRACTOR'S Contractor • Code ,Item AFFIDAVIT OF Surety D RELEASE OF LIENS Other D For Use with State of North Carolina Projects TO (OWNER) State of North Carolina through University of North Carolina Chapel Hill Chapel Hill, NC CONTRACT FOR: Plumbing ~----------------------------------~ CONTRACT DATE: PROJECT: UNC Person Hall Building S. Cameron Road Chapel Hill, NC State of: North Carolina County of: Johnston The undersigned, pursuant to Article 36 of the General Conditions of the Contract, hereby certifies that to the best of his knowledge, information and belief, the Releases or Waivers of Lien attached hereto include the contractor, all subcontractors, all suppliers of materials and equipment, and all performers of work, labor or services who have or may have liens against any property of the owner arising in any manner out of the performance of the contract referenced above . SUPPORTING DOCUMENTS ATTACHED HERETO: KIMBERLY P. HOLDER NOTARY PUBLIC Johnston County North Carolina My commission Expires CONTRACTOR: Southern Piping Company Address: By Dail Vice-President Subscribed and sworn to before me this 1st day of August, 2007 Notary Public~~~~~ My Commission Expi~: 06/30/2008 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • AFFIDAVIT OF CONTRACTOR (Release) State ofNorth Carolina County of Johnston I, George R. Dail, (title) Executive Vice-President of(company name) Southern Piping Company, being first duly sworn certify the (company name) Southern Piping Company was the Plumbing Contractor in connection with the construction of (project name) UNC Person Hall Building . Said improvements have been fully completed; to the best of my knowledge all payment for materials, services, or sub contracted work in connection with the contract have been satisfied, and no claims or liens exist against the Contractor in connection with this project. To the best of my knowledge, no claims or liens exist against any sub contractor or supplier, and if any appear afterwards (company name) Southern Piping Company hereby agrees to save harmless The State ofNorth Carolina through the University ofNorth Carolina at Chapel Hill . Signam~~ George R. Dail Title: Executive Vice-President Subscribed and sworn to before the undersigned, a Notary Public in and for the County and State qforesaid, this r' day of August. 2007 . KIMBERLY P. HOLDER NOTARY PUBLIC Johnston County North Carolina My ~JTl.ITfiSSion Expires My Commission Expires: 06/3012008 Notary Public~~ II II 08/01/2007 08:35 FAX 9199578768 SOUTHERN PIPING RALEIGH lg)003/UU4 II II II II II II II II II II II II II II II II II II II II II II II II II II II II II II II AFFIDAVIT OF CONTRACTOR (Release) State ofNorth Carolina County of Johnston I, George R. DaiL, (title) Executive Vice-President of (company name) Southern Piping Company. being firSt duly sworn certify the (company name) Southern Piping Company was the Plumbing Con1ra.ctor in connection with the construction of (project name) UNC Person Hall Building. Said improvements have been fully completed; to the best of my knowledge all payment for materials, service&, or sub contracted work. in connection with the contract have been satisfied, and no claims or liens exist against the Contractor in connection with this project. To the best of my knowledge, no claims cr liens exist against any sub contractor or supplier, and if any appear afterwards (company name) Southern Piping Company hereby agrees to save hanDless The State ofNorth Carolina through the Universi1;y ofNorth Carolina at Chapel Hill. s~S> George R. Dai1 Title: Executive Vice-President Subscribed and sworn to before the undersigned, a Notary Public in and for the County and State aforesaid. this Is day of August 2007. KIMBERLY P. HOLDER NOTARY PUBLIC Johnston County North Carolina My Commission Expires My Commission Expires: 0613012008 II 08/01/2007 08:35 FAX 9199578768 SOUTHERN PIPING RALEIGH ~004/004 II II II II II II II II II • II II II II II II II II II II II II II II II II II II II II II CONTRACTOR'S AFFIDAVIT OF RELEASE OF LIENS CONTRACTOR'S SECTION316 AFFIDAVIT OF RELEASE OF LIENS; Owner 0 Designer 0 Contractor B Code ,Item Surety 0 Other D For Use with State of North Carolina Projects TO (OWNER) State of North Carolina through University of North Carolina Chapel Hill Chapel Hill, NC CONTRACT FOR: Plumbing ~------------------------------~CONTRACT-DATE: PROJECT: UNC Person Hall Building s. Cameron Road Chapel Hill, NC State of: North Carolina County of: Johnston The undersigned, pursuant to Article 36 of the General Conditions of the Contract, hereby certifies that to the best of his knowledge, information and belief, the Releases or Waivers of Lien attached hereto include the contractor, all subcontractors, all suppliers of materials and equipment, and all performers of work, labor or services who have or may have liens against any property of the owner arising in any manner out of the performance of the contract referenced above. SUPPORTING DOCUMENTS ATTACHED HERETO: K1MBERLY P. HOLDER NOTARY PUBLIC Johnston County North Carolina My commission Expires CONTRACTOR: Southern Piping Company Address: By Subscribed and sworn to before me this 1st day of August, 2007 Notary Public~~~ My Commission Expi~:· 06/30/2008 • • • • 6-26-07;10:59AM;Caudle and Spears HAROLD C. SPEARS• CAUDLE & SPEARS, P.A . A'ITO.RNEYS AT LAW 2.600 INrERSTATB TOWER 121 WEST TRADE 5rREET CHARLOITE, NORIH CAROLINA 28202-5399 ;7043444786 # 1/ 1 • L CAMERON CAUDLE, JR. JeFfREY L IIEl.MS' a-IRISTOPHERJ.1CEIISACK TELEPHONE 7041377-1ZOG TB.E.COPIER 7041338-5858 • ERIC ALLEN ROGERS C. GRAINGER PISRCE.JR. IANM.BVRNE June 26, 2007 WRITER'S E-MAIL; clcebsack@caudlespears.com • • • • • • • • • • • • • • • • • • • • • • NATAUE D. POlTER- LLOYD C. CAUDLE (1930-20D3} Mr~ Christopher K. Fabrizio Mr. Lee Adams Fabco Construction, Inc. 144 N. Cherry Street, Suite 7 Kernersville, NC 27284 VIA FACSIMILE-336.992.1814 AND U.S. MAIL Re: Sparrow Enterprise, Jne. d/b/a Labor Finders v. Fabco Construction, Ine. Mecklenburg County: 07-CVS-9704 Our File No.: 3240.0061 Dear Messrs. Fabrizio and Adams: As I conveyed to each of you by telephone this morning, I have spoken to my client;, who has authorized me to extend the following settlement offer to Fabco in order to resolve this claim. Sparrow Enterprise, Inc. will accept the sum of$5,951.00, by bank/certified check, if received from Fabco on or before July 2, 2007. This amount represents the difference between SparroWs outstanding accollllt balance of $8,055.80, and the amounts clalmed by Fabeo arising out of repairs to the duct work in the amount of$2,104.80 . Upon receipt of these certified funds, Sparrow Enterprise will file a dismissal of its lawsuit against Fabco, thereby concluding the matter in its entirety. You may send the check directly to me, at the location listed above, and I will then prepare and file the necessary paper work with the COU%'4 and will provide you with a copy. Should you have any questions in the meantime, however, please feel free to contact me • CJUesm cc: Sparrow Enterprise, Inc . (via fax and mail) Sincerely yours, ((!~ & ~urr· rt ~J.~ • {'VD22Sm-1 1 • • • !! 09/21/2(107 18:42 FAX 704338585-8 CAUDLE & SPEARS .-: - • • • • • • • • • • • • • • • • • • HAROt.D C. SPEARS • L.CAteoN~.Jil. JEFi'REV L. HELMs CfiRISTOPHiiR J.l.OEEISACK ERIC ALLEN ROGERS C. SRAINGER PIERCE JR. IANM.~ ~T""--E D.I"'TTER- UOVD C. CAUDLE {11130-21103) Mr. Christopher K. Fabrizio Fabco Construction. Inc. 144 N. Cherry Street, Suite 7 Kernersville, NC 27284 CAUDLE&: SPEARS, P .A. A'ITORNEYS AT LAW 2600 INIERSrATii TOWER l21 WEST TRADE SlREET CHARLOI1E, NORTH CARO!JNA 2820U1!99 September 21,2007 TEI.EPKONE 704137'1-1200 TEI.ECOPleR 7041338-6858 WRITER'S &MAIL: npotter@caudlespear.9.;om VIA FACSIMILE (336) 992-1814 Re: Sparrow Enterprise, IDe.. d/b/a Labor F'mders v. Fab~ Comtrud:ioD, Inc. Dear Chris: Meeklenburg County: 07-CV8-9704 Our File No.: 3240.0061 Per our conversation, the following is a letter sent to you and Mr. Adams, dated June 26, 2007, memorializing Spaa-ow's settlement offer to Fabco. As I stated during our conversation, our client would like to resolve this matter as soon. as possible. As I have previously stated. we are unable to utilize the blank waiver futmS provided by yolll' office, as we lack information concerning the Contract. Please call Chris Loebsack or myself at your earliest convetli.ence, so that we can continue to work foiWard towards resolviu~ this matter amicably . : rn~OPf~ • .P~ • NDP!If encl. • • • • • • • • • (WQ:!2HIIM) 09/21/2007 16:43 FAX 7043385858 CAUDLE & SPEARS !g) 002 • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • .. AROLD C.. SPEAFIS • L CP.MEFION CA\JillE, JR. JEI'FREV'L HEI.NIS CliiUSTOPHER J. &.OEBSACK eRIC AJJ..af ROGERS C. GRAINGSl FIERCE, JR. IANM.BYRNQ ~TAI.Ii! D. P01TeR- LLOYD C. CAIIDI.E (1930-2Q03) CAUDLE & SPEARS, P.A . ATIORNEYSAT LAW 2600 INT.ERS!ATE Tow:ER 121 'WI!SI' TRADE Sl'REET CHARLOTIE, NOkm CAROLINA 28202.-53'1!1 June 26, 2007 1'EI..liPHONE 7041377·1200 TELECOPIER '7041338-6858 WJVrER'S !;-MAIL: cloebsack@caudlespears.com Mr. Christopher K. Fabrizio Mr. Lee Adams VIA FACSIMILE-336.992.1814 AND U.S. MAIL Fabco Construction, Inc . 144 N. Chary Street, Suite 7 Kernersville, NC 27284 Re: Sparrow Ellterprise, Iuc. d/b/a Labor Finders v. Fabeo Constnlction, lne. Mecldenburg CoWlty: {)7-CVS-9704 Our File No.: 3240.0061 Dear Messrs. Fal:nWo and Adams: As I conveyed to each of you by telephone this morning, I have spoken to my client, who has authorized me to extend the following settlement offi:r to Fabco in order to resolve this 'claim. Spmow Enterprise, Inc. will accept the sum of $5,951.00, by bank/certified check. if received from Fabco on or before July 2, 2007. This amount represents the difference between Sparrow's ou.tstandingaccount balance of$8,055.80, and the amounts claimed by Fabco arising ottt ofrepairs to tb.e ductwork in the amount of$2,104.80 . Upon receipt of these certified funds, Spmow Enterprise will file a dismissal of its lawsuit against Fabco, thereby concluding the matter :in its entirety. You may send the check directly to me, at the location listed above, and I will then prepare and file the necessary paper work with the court, and will provide you with a copy. Should you have any questions in the meantim~ however, please feel free to contact me . CJIJesm cc: Spmrow Enterprise, Inc . (via fax and mail) Sincerely yours, CAUDLE & SPEARS, P .A. Christopher J. Loebsack • • • • CAUDLE & SPEARS, P.A . ATIORNEYSAT LAW 2600 INTERSTATE TOWER HAROLD C. SPEARS • • L CAMERON CAUDLE. JR. 121 WESf TRADE SfREET CHARLOTTE, NOR'IH CAROLINA 28202-5399 TELEPHONE 7041377-1200 TELECOPIER 7041338-5858 JEFFREY L HElMS • CHRISTOPHeR J. LOEBSACK ERIC AUEN ROGERS October 8, 2007 WRITER'S E-MAIL: npotter@caudlespears.com C. GRAINGeR PieRCE, JR. IANM.BYRNE • NATAUE D. POTTER- • • ALSO UCENSED IN SOUTH CAROIJNA. -ALSO UCENSED IN MARYI.ANO • LLOYD C. CAUDLE {1930-Z003) • • • • • • • • • • • • • • • • • • • • • • • Mr. Christopher K. Fabrizio Fabco Construction, Inc. 144 N. Cherry Street, Suite 7 Kernersville, NC 27284 VIA FACSIIvllLE-336.992.1814 .A..NI) U.S. M..AJL Re: Sparrow Enterprise, Inc. d/b/a Labor Finders v. Fabco Construction, Inc. Dear Chris: Mecklenburg County: 07-CVS-9704 Our File No.: 3240.0061 I received your bank check in the amount of$5,951.00. I am in the process of drafting the lien waiver and having our client sign it. I will forward the signed waiver to you and file the necessary paper work with the court once the check clears the bank. Thank you again for your cooperation with this matter. If you have any questions, please call me . NDP/esm cc: Sparrow Enterprise, Inc. (via mail only) (W0230450-l ) . Potter • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • 09/21/2007 14:22 FAX 7043385838 f1AROLD C. SPEARS • L CAMeRON CAUDl.E. JR. JEFI'REY L HEUIIS CHRISTOPHERJ. LOEBSACK ERIC A1.LEH ROGERS C. GIWNGER I"'ERCE. JR. WIM.BVRNli NATAIJSD. POTTER: .. LLOYD C. CAUDlE !miD-211113} Mr. Lee Adams Fabco Construction, Inc. 144 N. Cherry Street,. Suite 7 Kernersville, NC 27284 CAUDLE & SPEARS, P .A • ATI'ORNEYSAT LAW :ZGCO ~An: TOWER 121 WESl' TRA'O! STlUiBT CHA.BLOTIE, NOR.lH CAROLINA 28202-5399 September 21, 2007 TELEPHONE 7041377-1200 TELECDPIER 704J338..585S WRITERS .e..u.AJI.: npatter@caudlespears.ccm VIA FACSIMILE (336) 992-1814 AND U.S. MAIL Re: Sparrow Enterprise, Inc.. d/b/a Labor Finders v. Fabco Coustructioll, Inc. Meddenbutg County: 07-CV8-9'7M Our Fdc No.: 3240 .. 0061 Dear Mr. Adams: To date we have not received a fi:illy completed Conditional Lien Waiver applicable to this situation fiom your office. The last document we received from Chris was insufficient in that it applies to a surety and was m tmconditiottal waiver, as opposed to a conditional wa:i"ter • In a. final attempt to resolve this matter, we will give Fabco until Wednesday, September 26, 2007 tQ provide us with a completed Conditional Lien Waiver applicable to this particular situation. If we do not receive it by close of business <m Wednesday, September 26, 2007, we will file m Entry of Default with the Court oo Thursday, September 27, 2007 . NDPilf cc: Sparrow Enterprise, Inc. (via U. S. mail) IVJVll9Bll7-1 J f\ ~· ~· u ;-· l ' Natalie D. Potter • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • SECTION 324 CERTIFICATE OF COMPLIANCE; PROJECT: Person Hall HVAC and Re-Roofing LOCATION: UNC-Chapel Hill BUDGET CODE: 40392 ITEM: 307 and 321 SCO ID#: -- OWNER: The University of North Carolina at Chapel Hill TYPE OF CONTRACT: Single Prime FINAL AMOUNT: $861 ,567.00 DATE OF FINAL ACCEPTANCE: 7 May 2007 CONTRACTOR:: Fabco Construction, Inc . I (we) certify that the work on the above-referenced project has been inspected in accordance with Chapter 133, Article 1, of the General Statutes, and that: (1) The inspections of the construction, repairs or installations have been conducted with the degree of care and professional skill and judgment ordinarily exercised by a member of my (our) profession; and (2) to the best of my (our) knowledge, and in my (our) professional opinion as an architect or engineer, the contractor has fulfilled the obligations of such plans, specifications and contract. Signed this Project Architect/HagerSmith Design. PA Title State of North Carolina, County of ___,\"""j);...;;.oJJ-=:;;..t..-=e.....:;;...__ ___________ _ Subscribed and sworn to before me this _\;_~!._~----day of 0 ~if 2001 Notary Public: _:_·'_J_~~~U!d2:J~~~::_~~~~~~~~~~L) My Commission Expires: _..:;;..__:,..........,~~~=----+-- • • • • • • • • • • • • • • • • • • • • • • • • • • • • • • SECTION 324 CERTIFICATE OF COMPLIANCE; PROJECT: HVAC & Re-Roofing Person Hall LOCATION: UNC at Chapel Hill, Chapel Hill, NC BUDGET CODE 40392 ITEM: 307 & 321 sco ID#: -------- OWNER: University of North Carolina at Chapel Hill TYPE OF CONTRACT Single Prime FINAL AMOUNT: $861,567.00 DATE OF FINAL ACCEPTANCE 7 May 2007 CONTRACTOR: Comfort Engineers (MechanicaO_ I (we) certify that the work on the above-referenced project has been inspected in accordance with Chapter 133, Article 1 , of the General Statutes, and that: (1) The inspections of the construction, repairs or installations have been conducted with the degree of care and professional skill and judgment ordinarily exercised by a member of my (our) profession; and (2) to the best of my (our) knowledge, and in my (our) professional opinion as an architect or engineer, the contractor has fulfilled the obligations of such plans, specifications and contract. Signed this ---=z.=--~---day of J#pJU"f-e't Zooe> Title State of North Carolina, County of ___,.~~~-e__--,------------ Subscribed and sworn to before me this ;)t:d Notary Public: ~~~--=;;.L.._=-.:l"""-'~"'-==------+ My Commission Expires: _---~.....;.___...~....___;~:...._---- Diannelti~ Notary Public Wake County, NC My Commission Expires Sept 16,2012 • 200801 02 Certificate of Compliance.doc •